Results 821-840 of 26,685 for speaker:David Cullinane

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: They also said that since September 2023, BAM has, on average, achieved 64% of its planned progress. In fact, when they were before the Oireachtas committee last year, they said it was 67% so what they were telling us last week was pretty much the same information. They also told us that of the 3,128 rooms which BAM has submitted as complete to its standard, none were completed to the...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: Okay but it was slightly less than €500 million. The Minister was the Minister for Health during all of that so when he paints the picture of four years, of 14 completion dates that have come and gone, four times over the last 12 months where BAM has missed its completion date, not providing the human resources to get the project done, no room of standard that is complete, and...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: So it was in the last week. I do not need the exact date.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: Okay, this was a number of weeks ago.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: When the Minister met them did he put it to them that they had missed their completion date 14 times, and four times in the last 12 months?

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: Did they accept that?

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: Did the Minister put it to them that they committed to 1,700 productive operatives but, according to the board, that they only provided, on average, 774? Essentially, the board and the Minister have been telling us that BAM is not committing the resources and this is why the completion dates have been missed. Did BAM accept, when the Minister met them last week, that it was the case they...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: But why not? The Minister went to great lengths to write to his Cabinet colleagues. I am not sure what the value was of doing that but the Minister sent a letter to his Cabinet colleagues, and while the Minister may not have used this language it was reported by the media as BAM holding the country to ransom. Those were the headlines coming out. The Minister did meet with the parent...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: I accept that, but I am also hearing from the Minister that they certainly were not agreeing with what the board was saying about BAM not fully resourcing the project. If BAM are not even prepared to accept the facts the board has presented to us, then how can I, the Minister, or anybody else on this committee have any confidence in what they are now telling us, which is that they will still...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: Perhaps I could just come back in. This project strikes to the heart of the credibility of the State in relation to how it funds and delivers big projects. There have been acres of coverage on this children's hospital and all of its failures. My focus is on getting the hospital built. I want it built for children. I publicly called on the contractor to do what is right and resource the...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: It told us that 16 months ago.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: I held on for a long time.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: The Minister does not need to hide behind the chair of the board. People will make up their own minds on his performance. I will leave it there. It was not appropriate to ask the chair essentially to answer a charge that I believe stands up or to cover the Minister's back.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: It was for the Minister to answer.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: My charge was that the Minister did not meet the contractor over the course of two years, which he did not.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: It is my understanding - the Minister might confirm this - that those claims centred around delays. While the total ask from BAM or the value BAM put on it might have been double what was awarded it was still awarded €108 million. How in God's name was it awarded €108 million if, as the board has stated, the delays were almost entirely or exclusively down to the contractor?...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: I am sorry, I asked the Minister.

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: I know it is, and it can be appealed to the court. The standing conciliator made a recommendation or however you want to put it. The conciliator adjudicated and made a recommendation in the amount of €108 million. The board contested this. I accept all of that. I went through this with the board. It was, however, the decision of the standing conciliator. Is that correct? The...

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: The second figure we have, again according to the board, was that since last September 2023 BAM has on average achieved 64% of its plan. Did the Minister put this to the parent company?

Joint Oireachtas Committee on Health: National Children’s Hospital: Discussion (9 Oct 2024)

David Cullinane: I want to deal with the funding side. I am aware that some of this was dealt with earlier, but I want to circle back on some of the issues that were raised. There is a huge number of outstanding claims. BAM has placed a value of about €800 million or whatever on these. That has been disputed by the Minister, the State and, obviously, the board. Where we have total agreement is...